marché public de travaux Construction de 4 bâtiments d'hébergement à Bricy (45) Base aérienne 123

contract notice

Following the summary about the notice 2024/S 002-003251 dispatched in the year 2024.


Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63
Contracting authority crescendo hg 1 info
France (FR) more authorities
Type of the contracting authority Ministry or any other national or federal authority
Main activity Defence
Type of contract Works
Main CPV code
Place of performance Loiret (FRB06) more
Country FR; - country: FR
Document type Contract notice
Procedure Open procedure
Type of bid Submission for all lots
Award criteria Lowest price
Regulation European Union, with participation of GPA countries
Publication date 2024-01-03 00:00:00
Deadline 2024-02-08 00:00:00
Values 24˙000˙000.00 EUR (estimated total)

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Deprecated: Function utf8_encode() is deprecated in /var/www/vhosts/fabiodisconzi.com/httpdocs/open-ted/function-open-ted.php on line 63

Section I: Contracting authority

I.1) Name and addresses please identify all contracting authorities responsible for the procedure

Official name
crescendo hg
Postal address
17 Place Sainte Hélène Châteauroux
Postal code: 36000
NUTS code: n.d. tipo 1 N.D. (n.d. tipo 1)
Country
France (FR)
Contact person
n.d. Telephone: +33 218477252 E-mail: achats@crescendo-conseil.org Fax: n.d.
Internet address(es)
Main address: http://www.marches.publics.gouv.fr
Address of the buyer profile: http://www.marches.publics.gouv.fr

I.4) Type of the contracting authority

Ministry or any other national or federal authority, including their regional or local subdivisions

I.5) Main activity

Defence

Section II: Object

II.1) Scope of the procurement

  • II.1.1) Title

    marché public de travaux Construction de 4 bâtiments d'hébergement à Bricy (45) Base aérienne 123

  • II.1.2) Main CPV code

    45000000 Construction work

  • II.1.3) Type of contract

    Works

  • II.1.4) Short description

    marché alloti à prix global et forfaitaire

    délai d'exécution de 34 mois à compter de l'ordre de service prévu en avril 2024

  • II.1.5) Estimated total value

    Value excluding VAT 24˙000˙000.00 Currency EUR

    for framework agreements or dynamic purchasing systems – estimated total maximum value for the entire duration of the framework agreement or dynamic purchasing system

  • II.1.6) Information about lots

    This contract is divided into lots

    yes

    Tenders may be submitted for all lots

II.2) Description

II.2.1) Title: installation de chantier - gros oeuvre [Lot No: [4]]

II.2.2) Additional CPV code(s)

Main CPV code

45223220 | Structural shell work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

installation de chantier - gros oeuvre

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: yes

pse no 01 : Matrice sur dalles béton armé préfabriquées - décor plafond chambres - lot 04

II.2.1) Title: couverture [Lot No: [6]]

II.2.2) Additional CPV code(s)

Main CPV code

45260000 | Roof works and other special trade construction works

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

couverture

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: métallerie - serrurerie [Lot No: [8]]

II.2.2) Additional CPV code(s)

Main CPV code

45262400 | Structural steel erection work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

métallerie - serrurerie

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: menuiseries intérieures [Lot No: [9]]

II.2.2) Additional CPV code(s)

Main CPV code

45421000 | Joinery work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

menuiseries intérieures

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: platrerie [Lot No: [10]]

II.2.2) Additional CPV code(s)

Main CPV code

45410000 | Plastering work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

platrerie

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: no

II.2.11) Information about options

Options: no

II.2.1) Title: revêtements de sols et faïence [Lot No: [11]]

II.2.2) Additional CPV code(s)

Main CPV code

45430000 | Floor and wall covering work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

revêtements de sols et faïence

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: peinture [Lot No: [12]]

II.2.2) Additional CPV code(s)

Main CPV code

45442100 | Painting work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

peinture

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: cabines préfabriquées [Lot No: [13]]

II.2.2) Additional CPV code(s)

Main CPV code

45223820 | Prefabricated units and components

Main site or place of performance: 45223820

II.2.4) Description of the procurement

cabines préfabriquées

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: yes

II.2.11) Information about options

Options: no

II.2.1) Title: plomberie - chauffage - ventilation [Lot No: [14]]

II.2.2) Additional CPV code(s)

Main CPV code

45330000 | Plumbing and sanitary works

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

plomberie - chauffage - ventilation

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: no

II.2.11) Information about options

Options: no

II.2.1) Title: ascenseurs [Lot No: [16]]

II.2.2) Additional CPV code(s)

Main CPV code

45313100 | Lift installation work

Main site or place of performance: base Aérienne 123, 45140 Saint Jean de la Ruelle

II.2.4) Description of the procurement

ascenseurs

II.2.5) Award criteria

Price is not the only award criterion and all criteria are stated only in the procurement documents

II.2.7) Duration of the contract, framework agreement or dynamic purchasing system

Duration in months: 34

This contract is subject to renewal: no

II.2.10) Information about variants

Variants will be accepted: no

II.2.11) Information about options

Options: no

Section III: Legal, economic, financial and technical information

III.1) Conditions for participation

III.3.1) Suitability to pursue the professional activity, including requirements relating to enrolment on professional or trade registers

List and brief description of conditions

se référer au règlement de consultation

III.1.2) Economic and financial standing

Selection criteria as stated in the procurement documents

III.1.3) Technical and professional ability

Selection criteria as stated in the procurement documents

Section IV: Procedure

IV.1) Description

IV.1.1) Type of procedure

Open procedure

IV.1.8) Information about the Government Procurement Agreement (GPA)

The procurement is covered by the Government Procurement Agreement: yes

IV.2) Administrative information

IV.2.2) Time limit for receipt of tenders or requests to participate

Date (dd/mm/yyyy): 2024-02-08

Local time (hh:mm): 12:00

IV.2.4) Languages in which tenders or requests to participate may be submitted

  • FR

IV.2.6)Minimum time frame during which the tenderer must maintain the tender

Duration in months: 4 MONTH (from the date stated for receipt of tender)

IV.2.7) Conditions for opening of tenders

Date (dd/mm/yyyy): 2024-02-08

Local time (hh:mm): 12:00

Section VI: Complementary information

VI.1) Information about recurrence

This is a recurrent procurement: no

VI.2) Information about electronic workflows

  • Electronic invoicing will be accepted

VI.1.3) Additional information

le maître d'ouvrage est l'esid de Rennes, représenté régionalement par le Pôle CO de Tours.

Il s'est entouré d'un maître d'ouvrage mandaté : Crescendo conseil agissant au nom et pour le compte de l'esid de Rennes.

La présente consultation concerne la relance pour la construction de 4 bâtiments d'hébergement à Bricy - base aérienne 123.

Une première consultation a été réalisée et la présente relance concerne uniquement les lots déclarés sans suite pour divers motifs d'intérêt général à savoir les lots :

Lot no4 Installation de chantier - gros-OEUvre ;

Lot no6 Couverture ;

Lot no8 Métallerie - serrurerie ;

Lot no9 Menuiseries intérieures ;

Lot no10 Plâtrerie ;

Lot no11 Revêtement de sols et faïence ;

Lot no12 Peinture ;

Lot no13 Cabines préfabriquées ;

Lot no14 Plomberie - chauffage - ventilation ;

Lot no16 Ascenseurs.

Parmi ces lots, seuls les lots 6 et 11 sont relancés à l'identique sans modification des caractéristiques techniques. Les autres lots ont subi des modifications qui sont indiquées de manière expresse dans les CCTP.

Critères de jugement pour tous les lots :

Prix 60 %

Valeur technique 40 %

VI.4) Procedures for review

VI.4.1) Review body

Official name
crescendo hg [n.d.]
Postal address
17 Place Sainte Hélène Châteauroux 36000 - nuts: n.d. tipo 1
Country
FR
Contact person
n.d. Telephone: +33 218477252 E-mail: achats@crescendo-conseil.org Fax: n.d.
Internet address(es)
Main address: http://www.marches.publics.gouv.fr | Address of the buyer profile: http://www.marches.publics.gouv.fr

VI.4.2) Body responsible for mediation procedures

Official name
crescendo hg [n.d.]
Postal address
17 Place Sainte Hélène Châteauroux 36000 - nuts: n.d. tipo 1
Country
FR
Contact person
n.d. Telephone: +33 218477252 E-mail: achats@crescendo-conseil.org Fax: n.d.
Internet address(es)
Main address: http://www.marches.publics.gouv.fr | Address of the buyer profile: http://www.marches.publics.gouv.fr

VI.4.3) Review procedure

Precise information on deadline(s) for review procedures

référé précontractuel : avant la signature du marché (article L551-1 et suivants du code de justice administrative) Recours pour excès de pouvoir : dans un délai de 2 mois à compter de la notification de la décision de rejet (article R421-1 et suivants du code de justice administrative) Recours de plein contentieux : dans un délai de 2 mois à compter de l'accomplissement des mesures de publicité concernant l'attribution du marché

VI.4.4) Service from which information about the review procedure may be obtained

Official name
crescendo hg [n.d.]
Postal address
17 Place Sainte Hélène Châteauroux 36000 - nuts: n.d. tipo 1
Country
FR
Contact person
n.d. Telephone: +33 218477252 E-mail: achats@crescendo-conseil.org Fax: n.d.
Internet address(es)
Main address: http://www.marches.publics.gouv.fr | Address of the buyer profile: http://www.marches.publics.gouv.fr

Date of dispatch of this notice

Date of dispatch of this notice (dd/mm/yyyy): 2023-12-29

You might be interested

Check raw information

View raw data from TED xml.

TECHNICAL_SECTION

1 RECEPTION_ID: 23-750415-001

1 DELETION_DATE: 20240208

1 FORM_LG_LIST: FR

1 COMMENTS: From Convertor

LINKS_SECTION

1 XML_SCHEMA_DEFINITION_LINK

1 OFFICIAL_FORMS_LINK

1 FORMS_LABELS_LINK

1 ORIGINAL_CPV_LINK

1 ORIGINAL_NUTS_LINK

CODED_DATA_SECTION

1 REF_OJS

2 COLL_OJ: S

2 NO_OJ: 2

2 DATE_PUB: 20240103

1 NOTICE_DATA

2 NO_DOC_OJS: 2024/S 002-003251

2 URI_LIST

3 --- URI_DOC   value: https://ted.europa.eu/udl?uri=TED:NOTICE:003251-2024:TEXT:FR:HTML

2 LG_ORIG: FR

2 ISO_COUNTRY

INFO: FR

2 IA_URL_GENERAL: http://www.marches.publics.gouv.fr

2 IA_URL_ETENDERING: http://www.marches.publics.gouv.fr

2 ORIGINAL_CPV: Construction work

INFOCODE: 45000000

2 ORIGINAL_CPV: Structural shell work

INFOCODE: 45223220

2 ORIGINAL_CPV: Roof works and other special trade construction works

INFOCODE: 45260000

2 ORIGINAL_CPV: Structural steel erection work

INFOCODE: 45262400

2 ORIGINAL_CPV: Joinery work

INFOCODE: 45421000

2 ORIGINAL_CPV: Plastering work

INFOCODE: 45410000

2 ORIGINAL_CPV: Floor and wall covering work

INFOCODE: 45430000

2 ORIGINAL_CPV: Painting work

INFOCODE: 45442100

2 ORIGINAL_CPV: Prefabricated units and components

INFOCODE: 45223820

2 ORIGINAL_CPV: Plumbing and sanitary works

INFOCODE: 45330000

2 ORIGINAL_CPV: Lift installation work

INFOCODE: 45313100

2 VALUES

3 --- VALUE   value: 24000000

1 CODIF_DATA

2 DS_DATE_DISPATCH: 20231229

2 DT_DATE_FOR_SUBMISSION: 20240208 12:00

2 AA_AUTHORITY_TYPE: Ministry or any other national or federal authority

INFOCODE: 1

2 TD_DOCUMENT_TYPE: Contract notice

INFOCODE: 3

2 NC_CONTRACT_NATURE: Works

INFOCODE: 1

2 PR_PROC: Open procedure

INFOCODE: 1

2 RP_REGULATION: European Union, with participation by GPA countries

INFOCODE: 5

2 TY_TYPE_BID: Submission for all lots

INFOCODE: 1

2 AC_AWARD_CRIT: The most economic tender

INFOCODE: 2

2 MA_MAIN_ACTIVITIES: Defence

INFOCODE: D

2 HEADING: 01A02

2 INITIATOR: 01

TRANSLATION_SECTION

1 ML_TITLES

2 ML_TI_DOC

3 --- TI_CY   value: Фpaнция

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Строителни и монтажни работи

2 ML_TI_DOC

3 --- TI_CY   value: Francie

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Stavební práce

2 ML_TI_DOC

3 --- TI_CY   value: Frankrig

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Bygge- og anlægsarbejder

2 ML_TI_DOC

3 --- TI_CY   value: Frankreich

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Bauarbeiten

2 ML_TI_DOC

3 --- TI_CY   value: Γαλλία

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Κατασκευαστικές εργασίες

2 ML_TI_DOC

3 --- TI_CY   value: France

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Construction work

2 ML_TI_DOC

3 --- TI_CY   value: Francia

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Trabajos de construcción

2 ML_TI_DOC

3 --- TI_CY   value: Prantsusmaa

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Ehitustööd

2 ML_TI_DOC

3 --- TI_CY   value: Ranska

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Rakennustyöt

2 ML_TI_DOC

3 --- TI_CY   value: France

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Travaux de construction

2 ML_TI_DOC

3 --- TI_CY   value: Fhrainc, an

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Construction work

2 ML_TI_DOC

3 --- TI_CY   value: Francuska

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Građevinski radovi

2 ML_TI_DOC

3 --- TI_CY   value: Franciaország

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Építési munkák

2 ML_TI_DOC

3 --- TI_CY   value: Francia

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Lavori di costruzione

2 ML_TI_DOC

3 --- TI_CY   value: Prancūzija

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Statybos darbai

2 ML_TI_DOC

3 --- TI_CY   value: Francija

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Celtniecības darbi

2 ML_TI_DOC

3 --- TI_CY   value: Franza

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Xogħol tal-kostruzzjoni

2 ML_TI_DOC

3 --- TI_CY   value: Frankrijk

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Bouwwerkzaamheden

2 ML_TI_DOC

3 --- TI_CY   value: Francja

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Roboty budowlane

2 ML_TI_DOC

3 --- TI_CY   value: França

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Construção

2 ML_TI_DOC

3 --- TI_CY   value: Franţa

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Lucrări de construcţii

2 ML_TI_DOC

3 --- TI_CY   value: Francúzsko

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Stavebné práce

2 ML_TI_DOC

3 --- TI_CY   value: Francija

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Gradbena dela

2 ML_TI_DOC

3 --- TI_CY   value: Frankrike

3 --- TI_TOWN   value: Châteauroux

3 TI_TEXT

L: 4 --- key: (P)   value: Anläggningsarbete

1 ML_AA_NAMES

2 AA_NAME: crescendo hg

FORM_SECTION

1 F02_2014

2 LEGAL_BASIS

INFO: 32014L0024

2 CONTRACTING_BODY

3 ADDRESS_CONTRACTING_BODY

L: 4 --- key: (OFFICIALNAME)   value: crescendo hg

L: 4 --- key: (ADDRESS)   value: 17 Place Sainte Hélène

L: 4 --- key: (TOWN)   value: Châteauroux

L: 4 --- key: (POSTAL_CODE)   value: 36000

INFO4: FR

4 COUNTRY

L: 4 --- key: (PHONE)   value: +33 218477252

L: 4 --- key: (E_MAIL)   value: achats@crescendo-conseil.org

L: 4 --- key: (URL_GENERAL)   value: http://www.marches.publics.gouv.fr

L: 4 --- key: (URL_BUYER)   value: http://www.marches.publics.gouv.fr

3 DOCUMENT_FULL

3 --- URL_DOCUMENT   value: http://www.marches.publics.gouv.fr

3 ADDRESS_FURTHER_INFO_IDEM

3 --- URL_PARTICIPATION   value: http://www.marches.publics.gouv.fr

3 CA_TYPE

3 CA_ACTIVITY

2 OBJECT_CONTRACT

3 TITLE

L: 4 --- key: (P)   value: marché public de travaux Construction de 4 bâtiments d'hébergement à Bricy (45) Base aérienne 123

3 CPV_MAIN

4 CPV_CODE

3 TYPE_CONTRACT

3 SHORT_DESCR

L: 4 --- key: (P)   value: marché alloti à prix global et forfaitaire

L: 4 --- key: (P)   value: délai d'exécution de 34 mois à compter de l'ordre de service prévu en avril 2024

3 --- VAL_ESTIMATED_TOTAL   value: 24000000

3 LOT_DIVISION

4 LOT_ALL

3 OBJECT_DESCR

4 TITLE

5 P: installation de chantier - gros oeuvre

L: 4 --- key: (LOT_NO)   value: 4

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: installation de chantier - gros oeuvre

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 OPTIONS

4 OPTIONS_DESCR

5 P: pse no 01 : Matrice sur dalles béton armé préfabriquées - décor plafond chambres - lot 04

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: couverture

L: 4 --- key: (LOT_NO)   value: 6

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: couverture

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: métallerie - serrurerie

L: 4 --- key: (LOT_NO)   value: 8

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: métallerie - serrurerie

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: menuiseries intérieures

L: 4 --- key: (LOT_NO)   value: 9

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: menuiseries intérieures

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: platrerie

L: 4 --- key: (LOT_NO)   value: 10

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: platrerie

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 NO_ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: revêtements de sols et faïence

L: 4 --- key: (LOT_NO)   value: 11

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: revêtements de sols et faïence

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: peinture

L: 4 --- key: (LOT_NO)   value: 12

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: peinture

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: cabines préfabriquées

L: 4 --- key: (LOT_NO)   value: 13

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: 45223820

4 SHORT_DESCR

5 P: cabines préfabriquées

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: plomberie - chauffage - ventilation

L: 4 --- key: (LOT_NO)   value: 14

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: plomberie - chauffage - ventilation

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 NO_ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

3 OBJECT_DESCR

4 TITLE

5 P: ascenseurs

L: 4 --- key: (LOT_NO)   value: 16

4 CPV_ADDITIONAL

5 CPV_CODE

4 MAIN_SITE

5 P: base Aérienne 123, 45140 Saint Jean de la Ruelle

4 SHORT_DESCR

5 P: ascenseurs

4 AC

5 AC_PROCUREMENT_DOC

L: 4 --- key: (DURATION)   value: 34

4 NO_RENEWAL

4 NO_ACCEPTED_VARIANTS

4 NO_OPTIONS

4 NO_EU_PROGR_RELATED

2 LEFTI

3 SUITABILITY

L: 4 --- key: (P)   value: se référer au règlement de consultation

3 ECONOMIC_CRITERIA_DOC

3 TECHNICAL_CRITERIA_DOC

2 PROCEDURE

3 PT_OPEN

3 CONTRACT_COVERED_GPA

3 --- DATE_RECEIPT_TENDERS   value: 2024-02-08

3 --- TIME_RECEIPT_TENDERS   value: 12:00

3 LANGUAGES

INFO4: FR

4 LANGUAGE

3 --- DURATION_TENDER_VALID   value: 4

3 OPENING_CONDITION

L: 4 --- key: (DATE_OPENING_TENDERS)   value: 2024-02-08

L: 4 --- key: (TIME_OPENING_TENDERS)   value: 12:00

2 COMPLEMENTARY_INFO

3 NO_RECURRENT_PROCUREMENT

3 EINVOICING

3 INFO_ADD

L: 4 --- key: (P)   value: le maître d'ouvrage est l'esid de Rennes, représenté régionalement par le Pôle CO de Tours.

L: 4 --- key: (P)   value: Il s'est entouré d'un maître d'ouvrage mandaté : Crescendo conseil agissant au nom et pour le compte de l'esid de Rennes.

L: 4 --- key: (P)   value: La présente consultation concerne la relance pour la construction de 4 bâtiments d'hébergement à Bricy - base aérienne 123.

L: 4 --- key: (P)   value: Une première consultation a été réalisée et la présente relance concerne uniquement les lots déclarés sans suite pour divers motifs d'intérêt général à savoir les lots :

L: 4 --- key: (P)   value: Lot no4 Installation de chantier - gros-OEUvre ;

L: 4 --- key: (P)   value: Lot no6 Couverture ;

L: 4 --- key: (P)   value: Lot no8 Métallerie - serrurerie ;

L: 4 --- key: (P)   value: Lot no9 Menuiseries intérieures ;

L: 4 --- key: (P)   value: Lot no10 Plâtrerie ;

L: 4 --- key: (P)   value: Lot no11 Revêtement de sols et faïence ;

L: 4 --- key: (P)   value: Lot no12 Peinture ;

L: 4 --- key: (P)   value: Lot no13 Cabines préfabriquées ;

L: 4 --- key: (P)   value: Lot no14 Plomberie - chauffage - ventilation ;

L: 4 --- key: (P)   value: Lot no16 Ascenseurs.

L: 4 --- key: (P)   value: Parmi ces lots, seuls les lots 6 et 11 sont relancés à l'identique sans modification des caractéristiques techniques. Les autres lots ont subi des modifications qui sont indiquées de manière expresse dans les CCTP.

L: 4 --- key: (P)   value: Critères de jugement pour tous les lots :

L: 4 --- key: (P)   value: Prix 60 %

L: 4 --- key: (P)   value: Valeur technique 40 %

3 ADDRESS_REVIEW_BODY

L: 4 --- key: (OFFICIALNAME)   value: tribunal administratif d'orléans

L: 4 --- key: (ADDRESS)   value: 28 rue de la Bretonnerie

L: 4 --- key: (TOWN)   value: Orléans Cedex 1

L: 4 --- key: (POSTAL_CODE)   value: 45057

INFO4: FR

4 COUNTRY

L: 4 --- key: (PHONE)   value: +33 238775900

L: 4 --- key: (E_MAIL)   value: greffe.ta-orleans@juradm.fr

L: 4 --- key: (URL)   value: http://orleans.tribunal-administratif.fr

3 ADDRESS_MEDIATION_BODY

L: 4 --- key: (OFFICIALNAME)   value: comité consultatif national de règlement amiable des différends relatifs aux marchés publics

L: 4 --- key: (ADDRESS)   value: bâtiment Condorcet - télédoc 353 6 rue Louise Weiss

L: 4 --- key: (TOWN)   value: Paris Cedex 1

L: 4 --- key: (POSTAL_CODE)   value: 75703

INFO4: FR

4 COUNTRY

L: 4 --- key: (PHONE)   value: +33 144972506

L: 4 --- key: (E_MAIL)   value: ccra.daj@finances.gouv.fr

3 REVIEW_PROCEDURE

L: 4 --- key: (P)   value: référé précontractuel : avant la signature du marché (article L551-1 et suivants du code de justice administrative) Recours pour excès de pouvoir : dans un délai de 2 mois à compter de la notification de la décision de rejet (article R421-1 et suivants du code de justice administrative) Recours de plein contentieux : dans un délai de 2 mois à compter de l'accomplissement des mesures de publicité concernant l'attribution du marché

3 ADDRESS_REVIEW_INFO

L: 4 --- key: (OFFICIALNAME)   value: tribunal administratif d'orléans

L: 4 --- key: (ADDRESS)   value: 28 rue de la Bretonnerie

L: 4 --- key: (TOWN)   value: Orléans Cedex 1

L: 4 --- key: (POSTAL_CODE)   value: 45057

INFO4: FR

4 COUNTRY

L: 4 --- key: (PHONE)   value: +33 238775900

L: 4 --- key: (E_MAIL)   value: greffe.ta-orleans@juradm.fr

L: 4 --- key: (URL)   value: http://orleans.tribunal-administratif.fr

3 --- DATE_DISPATCH_NOTICE   value: 2023-12-29

26+1